EPC合同條件(中英文對照版)

《EPC合同條件(中英文對照版)》由會員分享，可在線閱讀，更多相關(guān)《EPC合同條件(中英文對照版)（106頁珍藏版）》請?jiān)谘b配圖網(wǎng)上搜索。

1、　　　　　　　　　　　　　　　　　　　　　　　　　　　　　　　　　 CONTENTS 目 錄 1　General Provisions　一般規(guī)定 5 1.1　Definitions　定義 5 1.2　Interpretation　解釋 10 1.3　Communications　通信交流 11 1.4　Law and Language　法律和語言 12 1.5　Priority of Document　文件優(yōu)先次序 12 1.6　Contract Agreement　合同協(xié)議書 12 1.7　Assignment　權(quán)益轉(zhuǎn)讓 13 1.8　Care and Sup

2、ply of Document　文件的照管和提供 13 1.9　Confidentiality　保密性 14 1.10　Employer’s Use of Contractor’s Documents　雇主使用承包商文件 14 1.11　Contractor’s Use of Employer’s Documents　承包商使用雇主文件 15 1.12　Confidential Details　保密事項(xiàng) 15 1.13　Compliance with Laws　遵守法律 15 1.14　Joint and Several Liability　共同的和各自的責(zé)任 16 2　The

3、Employer　雇主 16 2.1　Right of Access to the Site　現(xiàn)場進(jìn)入權(quán) 16 2.2　Permits, Licences or Approves　許可、執(zhí)照或批準(zhǔn) 17 2.3　Employer’s personnel　雇主人員 18 2.4　Employer’s Financial Arrangements　雇主的資金安排 18 2.5　Employer’s Claims　雇主的索賠 18 3　The Employer’s Administration　雇主的管理 19 3.1　The Employer’s Representative　雇主代

4、表 19 3.2　The Employer’s personnel　其他雇主人員 20 3.3　Delegated Persons　受托人員 20 3.4　Instructions　指示 21 3.5　Determinations　確定 21 4　The Contractor　承包商 21 4.1　The Contractor’s General Obligations　承包商的一般義務(wù) 22 4.2　Performance security　履約擔(dān)保 22 4.3　Contractor’s Representative　承包商代表 23 4.4　Subcontractors

5、　分包商 24 4.5　Nominated Subcontractors　指定的分包商 25 4.6　Co-operation　合作 25 4.7　Setting out　放線 26 4.8　Safety procedures　安全程序 26 4.9　Quality Assurance　質(zhì)量保證 27 4.10　Site Data　現(xiàn)場數(shù)據(jù) 27 4.11　Sufficiency of the Contract Price　合同價格 28 4.12　Unforeseeable Difficulties　不可預(yù)見的困難 28 4.13　Rights of way and Fac

6、ilities　道路通行權(quán)于設(shè)施 28 4.14　Avoidance of Interference　避免干擾 29 4.15　Access Route　進(jìn)場通路 29 4.16　Transport of Goods　貨物運(yùn)輸 30 4.17　Contractor’s Equipment　承包商設(shè)備 30 4.18　Protection of the Environment　環(huán)境保護(hù) 30 4.19　Electricity, Water and Gas　電、水和燃?xì)?31 4.20　Employer’s Equipment and Free-Issue Material　雇主設(shè)備

7、和免費(fèi)供應(yīng)的材料 31 4.21　Progress Reports　進(jìn)度報告 32 4.22　Security of the Site　現(xiàn)場保安 33 4.23　Contractor’s Operations on Site　承包商的現(xiàn)場作業(yè) 34 4.24　Fossils　化石 34 5　Design　設(shè)計 35 5.1　General Design Obligations　設(shè)計義務(wù)一般要求 35 5.2　Contractor’s Documents　承包商文件 36 5.3　Contractor’s Undertaking　承包商的承諾 37 5.4　Technical

8、Standards and Regulations　技術(shù)標(biāo)準(zhǔn)和法規(guī) 37 5.5　Training　培訓(xùn) 38 5.6　As-Built Documents　竣工文件 38 5.7　Operation and Maintenance Manuals　操作和維修手冊 39 5.8　Design Error　設(shè)計錯誤 39 6　Staff and Labour　員工 39 6.1　Engagement of Staff and Labour　員工的雇用 40 6.2　Rates of Wages and Conditions of Labour　工資標(biāo)準(zhǔn)和勞動條件 40 6.3　P

9、ersons in the Service of Employer　為雇主服務(wù)的人員 40 6.4　Labour Laws　勞動法 40 6.5　Working Hours　工作時間 41 6.6　Facilities for Staff and Labour　為員工提供設(shè)施 41 6.7　Health and Safety　健康和安全 41 6.8　Contractor’s Superintendence　承包商的監(jiān)督 42 6.9　Contractor’s Personnel　承包商人員 42 6.10　Records of contractor’s Personnel an

10、d Equipment　承包商人員和設(shè)備的記錄 43 6.11　Disorderly Conduct　無序行為 43 7　Plant, Materials and Workmanship　生產(chǎn)設(shè)備、材料和工藝 43 7.1　Manner of Execution　實(shí)施方法 43 7.2　Samples　樣品 44 7.3　Inspection　檢驗(yàn) 44 7.4　Testing　試驗(yàn) 45 7.5　Rejection　拒收 46 7.6　Remedial Work　修補(bǔ)工作 46 7.7　Ownership of Plant and Materials　生產(chǎn)設(shè)備和材料的所有權(quán)

11、 47 7.8　Royalties　土地(礦區(qū))使用費(fèi) 47 8　Commencement,Delays and Suspension　開工、延誤和暫停 48 8.1　Commencement of Works　工程的開工 48 8.2　Time for Completion　竣工時間 48 8.3　Programme　進(jìn)度計劃 49 8.4　Extension of Time for Completion　竣工時間延長 50 8.5　Delays Caused by Authorities　當(dāng)局造成的延誤 50 8.6　Rate of Progress　工程進(jìn)度 51 8.

12、7　Delay Damages　誤期損害賠償費(fèi) 51 8.8　Suspension of Work　暫時停工 52 8.9　Consequences of Suspension　暫停的后果 52 8.10　Payment for Plant and Materials in Event of Suspension　暫停時對生產(chǎn)設(shè)備和材料的付款 53 8.11　Prolonged Suspension　托長的暫停 53 8.12　Resumption of Work　復(fù)工 53 9　Tests on Completion　竣工試驗(yàn)　 54 9.1　Contractor’s Obli

13、gations　承包商的義務(wù) 54 9.2　Delayed Tests　延誤的試驗(yàn) 55 9.3　Retesting　重新試驗(yàn) 55 9.4　Failure to Pass Tests on Completion　未能通過竣工試驗(yàn) 56 10　Employer’s Taking Over　雇主的接收　 56 10.1　Taking Over of the Works and Sections　工程和分項(xiàng)工程的接收 56 10.2　Taking Over of Parts of the Works　部分工程的接收 57 10.3　Interference with Tests on

14、 Completion　對竣工試驗(yàn)的干擾 57 11　Defects Liability　缺陷責(zé)任 58 11.1　Completion of Outstanding Work and Remedying Defects　完成掃尾工作和修補(bǔ)缺陷 58 11.2　Cost of Remedying Defects　修補(bǔ)缺陷的費(fèi)用 59 11.3　Extension of Defects Notification Period　缺陷通知期的延長 59 11.4　Failure to Remedy Defects　未能修補(bǔ)的缺陷 60 11.5　Removal of Defective

15、Work　移出有缺陷的工程 60 11.6　Further Tests　進(jìn)一步試驗(yàn) 61 11.7　Right of Access　進(jìn)入權(quán) 61 11.8　Contractor to Search　承包商調(diào)查 61 11.9　Performance Certificate　履約證書 62 11.10　Unfulfilled Obligations　未履行的義務(wù) 62 11.11　Clearance of Site　現(xiàn)場清理 62 12　Tests after Completion　竣工后試驗(yàn) 63 12.1　Procedure for Tests after Completio

16、n　竣工后試驗(yàn)的程序 63 12.2　Delayed Tests　延誤的試驗(yàn) 64 12.3　Retesting　重新試驗(yàn) 64 12.4　Failure to Pass Tests after Completion　未能通過的竣工后試驗(yàn) 65 13　Variations and Adjustments　變更和調(diào)整 66 13.1　Right to Vary　變更權(quán) 66 13.2　Value Engineering　價值工程 66 13.3　Variation Procedure　變更程序 66 13.4　Payment in Applicable Currencies　以適

17、用貨幣支付 67 13.5　Provisional Sums　暫列金額 67 13.6　Daywork　計日工作 68 13.7　Adjustments for Changes in Legislation　因法律改變的調(diào)整 69 13.8　Adjustments for Changes in Cost　因成本改變的調(diào)整 70 14　Contract price and Payment　合同價格和支付 70 14.1　The Contract Price　合同價格 70 14.2　Advance payment　預(yù)付款 70 14.3　Application for Inter

18、im Payments　期中付款的申請 72 14.4　Schedule of Payments　付款價格表 73 14.5　Plant and Materials intended for the Works　擬用于工程的生產(chǎn)設(shè)備和材料 73 14.6　Interim Payments　期中付款 74 14.7　Timing of Payments　付款的時間安排 74 14.8　Delayed Payment　延誤的付款 75 14.9　Payment of Retention Money　保留金支付 75 14.10　Statement at Completion　施工報表

19、 76 14.11　Application for Final Payment　最終付款的申請 76 14.12　Discharge　結(jié)清證明 77 14.13　Final Payment　最終付款 77 14.14　Cessation of Employer’s Liability　雇主責(zé)任的中止 78 14.15　Currencies of Payment　支付的貨幣 78 15　Termination by Employer　由雇主終止 79 15.1　Notice to Correct　通知改正 79 15.2　Termination by Employer　由雇主終止

20、 79 15.3　Valuation at Date of Termination　終止日期時的估價 81 15.4　Payment after Termination　終止后的付款 81 15.5　Employer’s Entitlement to Termination　雇主終止的權(quán)利 82 16　Suspension and termination by Contractor由承包商暫停和終止 82 16.1　Contractor’s Entitlement to Suspend Work　承包商暫停工作的權(quán)利 82 16.2　Termination by Contracto

21、r　由承包商終止 83 16.3　Cessation of Work and Removal of Contractor’s Equipment　停止工作和承包商設(shè)備的撤離 84 16.4　Payment on Termination　終止時的付款 84 17　Risk and Responsibility　風(fēng)險和職責(zé) 85 17.1　Indemnities　保障 85 17.2　Contractor’s Care of the Works　承包商對工程的照管 86 17.3　Employer’s Risks　雇主的風(fēng)險 87 17.4　Consequence of Employ

22、er’s Risks　雇主風(fēng)險的后果 87 17.5　Intellectual and Industrial Property Rights　知識產(chǎn)權(quán)和工業(yè)產(chǎn)權(quán) 88 17.6　Limitation of Liability　責(zé)任限度 89 18　Insurance　保險 89 18.1　General Requirements for Insurances　有關(guān)保險的一般要求 89 18.2　Insurance for Works and Contractor’s Equipment　工程和承包商設(shè)備的保險 91 18.3　Insurance against Injury to

23、Persons and Damage to Property　人身傷害和財產(chǎn)損害險 93 18.4　Insurance for Contractor’s Personnel　承包商人員的保險 94 19　Force Majeure　不可抗力　 94 19.1　Definition of Force Majeure　不可抗力的定義 95 19.2　Notice of Force Majeure　不可抗力的通知 96 19.3　Duty to Minimise Delay　將延誤減至最小的義務(wù) 96 19.4　Consequences of Force Majeure　不可抗力的后果

24、96 19.5　Force Majeure Affecting Subcontractor　不可抗力影響分包商 97 19.6　Optional Termination, Payment and Release　自主選擇終止、支付和解除 97 19.7　Release from Performance under the Law　根據(jù)法律解除履約 98 20　Claims, Disputes and Arbitration　索賠、爭端和仲裁 98 20.1　Contractor’s Claims　承包商的索賠 99 20.2　Appointment of the Dispute A

25、djudication Board　爭端裁決委員會的任命 100 20.3　Failure to Agreement Dispute Adjudication Board　對爭端裁決委員會未能取得一致時 102 20.4　Obtaining Dispute Adjudication Board’s Decision　取得爭端裁決委員會的決定 102 20.5　Amicable Settlement　友好解決 103 20.6　Arbitration　仲裁 104 20.7　Failure to Comply with Dispute Adjudication Board’s Deci

26、sion　未能遵守爭端裁決委員會的決定 105 20.8　Expiry of Dispute Adjudication Board’s Appointment　爭端裁決委員會任命期滿 105 1　General Provisions 一般規(guī)定 1.1　Definitions 定義 In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressi

27、ons shall have the meaning stated. Words indicating persons or parties include corporation and other legal entities, except where the context requires otherwise. 在合同條件（“本條件”），包括專用條件和通用條件中，下列詞語和措辭應(yīng)具有以下所述的含義.除上下文另有要求外，文中人員或當(dāng)事各方等詞語包括公司和其他合法實(shí)體. 1.1.1　The Contract consignee 合同 1.1.1.1　“Contract” mea

28、ns the Contract Agreement, these Conditions, the Employer’s Requirement, the Tender, and further document (if any) which are listed in the Contract Agreement. “合同”系指合同協(xié)議書、本條件、雇主要求、投標(biāo)書和合同協(xié)議書列出的其他文件（如果有）. 1.1.1.2　“Contract Agreement” means the contract agreement referred to in Sub-Clause 1.6 [Contra

29、ct Agreement], including any annexed memoranda. “合同協(xié)議書”系指第1.6款[合同協(xié)議書]中所述的合同協(xié)議書及所附各項(xiàng)備忘錄. 1.1.1.3　“Employer’s requirements” means the document entitled employer’s requirements, as included in the Contract, and any additions and modifications to such document in accordance with the Contract. Such doc

30、ument specifies the purpose, scope, and/or design and/or other technical criteria, for the Works. “雇主要求”系指合同中包括的，題為雇主要求的文件，其中列明工程的目標(biāo)、范圍、和（或）設(shè)計和（或）其他技術(shù)標(biāo)準(zhǔn)，以及按合同對此項(xiàng)文件所作的任何補(bǔ)充和修改. 1.1.1.4　“Tender” means the Contractor’s signed offer for the Works and all other documents which the Contractor submitted

31、therewith (other than these Conditions and Employer’s Requirements, if so submitted), as included in the Contract. “投標(biāo)書”系指包含在合同中的由承包商提交的為完成工程簽署的報價，以及隨同提交的所有其他文件（本條件和雇主要求除外，如同時提交）. 1.1.1.5　“Performance Guarantees” and “Schedule of payments” mean the documents so named (if any), as included in the C

32、ontract. “履約保證”和“付款計劃表”系指合同中包括的具有上述名稱的文件（如果有）. 1.1.2　Parties and Persons 各方和人員 1.1.2.1　“Party” means the Employer or the Contractor, as the context requires. “當(dāng)事方（或一方）”根據(jù)上下文需要，或指雇主，或指承包商。 1.1.2.1　“Employer” means the person named as employer in the Contract Agreement and the legal successors i

33、n title to this person. “雇主”系指在合同協(xié)議書中被稱為雇主的當(dāng)事人及其財產(chǎn)所有權(quán)的合法繼承人。 1.1.2.3　“Contractor” means the person(s) named as contractor in the Contract Agreement and the legal successors in title to this person(s). “承包商”系指合同協(xié)議書中被稱為承包商的當(dāng)事人及其財產(chǎn)所有權(quán)的合法繼承人。 1.1.2.4　“Employer’s Representative” means the person name

34、d by the Employer in the Contract or appointed from time to time by the Employer under Sub-Clause 3.1 [ the Employer’s Representative], who acts on behalf of the Employer. “雇主代表”系指由雇主在合同中指名的人員，或有時由雇主根據(jù)第3.1款［雇主代表的人員］的規(guī)定任命為其代表的人員。 1.1.2.5　“Contractor’s Representative” means the person named by the C

35、ontractor in the Contract or appointed from time to time by the Contractor Sub-Clause 4.3 [the Contractor’s Representative], who acts on behalf of the Contractor. “承包商代表”系指由承包商在合同中指名的人員，或有時由承包商根據(jù)第4.3款[承包商代表]的規(guī)定任命為其代表的人員。 1.1.2.6　“Employer’s Personnel” means the Employer’s Representative, the assis

36、tants referred to in Sub-Clause 3.2 [Other Employer’s Personnel] and all other staff, labour and other employees of the Employer and of the Employer’s Representative; and any other personnel notified to the Contractor, by the Employer or the Employer’s Representative, as Employer’s Personnel. “雇主人員

37、”系指雇主代表、第3.2款[其他雇主人員]中提到的助手、以及雇主和雇主代表的所有其他職員、工人和其他雇員，以及雇主或雇主代表通知承包商作為雇主人員的任何其他人員。 1.1.2.7　“Contractor’s Personnel” means the Contractor’s Representative and all personnel whom the Contractor utilizes on Site, who may include the staff, labour and other employees of the Contractor and of each Subcon

38、tractor, and any other personnel assisting the Contractor in the execution of the works. “承包商人員”系指承包商代表和承包商在現(xiàn)場聘用的所有人員，包括承包商和每個分包商的職員、工人和其他雇員，以及所有其他幫助承包商實(shí)施工程的人員。 1.1.2.8　“Subcontractor” means any person named in the Contract as a subcontractor, or any person appointed as a subcontractor, for a part

39、 of the Works; and the legal successors in title to each of these persons. “分包商”系指為完成部分工程，在合同中指名為分包商、或被任命為分包商的任何人員，以及這些人員財產(chǎn)所有權(quán)的合法繼承人。 1.1.2.9　“DAB” means the person or three persons so named in the Contract, or other person(s) appointed under Sub-Clause 20.2 [Appointment of the Dispute Adjudicatio

40、n Board] or Sub-Clause 20.3 [Failure to Agree Dispute Adjudication Board]. “DAB（爭端裁決委員會）”系指在合同中如此指名的一名或三名人員，或根據(jù)第20.2款[爭端裁決委員會的任命]或第20.3款[對爭端裁決委員會未能取得一致]的規(guī)定任命的其他人員。 1.1.2.10　“FIDIC” means the Federation International des Ingenieurs-Conseils, the international federation of consulting engineers. “

41、菲迪克（FIDIC）”系指國際咨詢工程師聯(lián)合會。 1.1.3　Dates ,Test, Periods and Completion 日期、試驗(yàn)、期限和竣工 1.1.3.1　“Base Date” means the date 28 days prior to the latest date for submission of the Tender. “基準(zhǔn)日期”系指遞交投標(biāo)書截止前28天的日期。 1.1.3.2　“Commencement Date” means the date notified under Sub-Clause 8.1 [Commencement of Work

42、s], unless otherwise defined in the Contract Agreement. “開工日期”系指根據(jù)第8.1款[工程的開工]的規(guī)定通知的日期，合同協(xié)議書中另有規(guī)定的除外。 1.1.3.3　“Time for Completion” means the time for completing the Works or a Section (as the case may be) under Sub-Clause 8.2 [Time for Completion], as stated in the Particular Conditions (with any

43、 extension under Sub-Clause 8.4 [Execution of Time for Completion]), calculated from the Commencement Date. “竣工時間”系指專用條件中規(guī)定的，自開工日期算起，至工程或某分項(xiàng)工程（視情況而定）根據(jù)第8.2款[竣工時間]規(guī)定的要求竣工（連同根據(jù)第8.4款[竣工時間的延長]的規(guī)定提出的任何延長期）的全部時間。 1.1.3.4　“Tests on Completion” means the tests which are specified in the Contract or agree

44、d by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the works or a Section (as the case may be) are taken over by the Employer. “竣工試驗(yàn)”系指在合同中規(guī)定或雙方商定的，或按指示作為一項(xiàng)變更的，在工程或某分項(xiàng)工程（視情況而定）被雇主接收前，根據(jù)第9條[竣工試驗(yàn)]的要求，進(jìn)行的試驗(yàn)。 1.1.3.5　“Taking-Over Certi

45、ficate” means a certificate issued under Clause 10 [Employer’s Taking Over]. “接收證書”系指根據(jù)第10條[雇主接收]的規(guī)定頒發(fā)的證書。 1.1.3.6　“Tests after Completion” means the tests (if any) are specified in the Contract and which are carried out under Clause 12 [Tests after Completion] after the works or a Section (as th

46、e case may be) are taken over by the Employer. “竣工后試驗(yàn)”系指在合同中規(guī)定的，在工程或某分項(xiàng)工程（視情況而定）被雇主接收后，根據(jù)第12條[竣工后試驗(yàn)]的要求，進(jìn)行的試驗(yàn)（如果有）。 1.1.3.7　“Defects Notification Period” means the period for notifying defects in the Works or a Section (as the case may be) under Sub-Clause 11.1 [Completion of Understanding Works a

47、nd Remedying Defects], as stated in the Particular Conditions (with any extension under Sub-Clause 11.3 [Extension of Defects Notification Period]), calculated from the date on which the Works or Section is competed as certified under Sub-Clause 10.1 [Taking Over of the Works and Sections]. If no su

48、ch period is stated in the Particular Conditions, the period shall be one year. “缺陷通知期限”系指專用條件中規(guī)定的，自工程或某分項(xiàng)工程（視情況而定）根據(jù)第10.1款[工程和分項(xiàng)工程的接收]的規(guī)定證明的竣工日期算起，至根據(jù)第11.1款[完成掃尾工作和修補(bǔ)缺陷]的規(guī)定通知工程或分項(xiàng)工程存在缺陷的期限（連同根據(jù)第11.3款[缺陷通知期限的延長]的規(guī)定提出的任何延長期）。如果專用條件中沒有提出這一期限，該期限應(yīng)為一年。 1.1.3.8　“Performance Certificate” means the certi

49、ficate issued under Sub-Clause 11.9 [Performance Certificate]. “履約證書”系指根據(jù)第11.9款[履約證書]的規(guī)定頒發(fā)的證書。 1.1.3.9　“day” means a calendar day and “year” means 365 days. “日（天）”系指一個日歷日，“年”系指365天。 1.1.4　Money and Payments 款項(xiàng)與付款 1.1.4.1　“Contract Price” means the agreed amount stated in the Contract Agreement

50、 for the design, execution and completion of the Works and the remedying of any defects, and includes adjustment (if any) in accordance with the contract. “合同價格”系指在合同協(xié)議書中寫明的、經(jīng)商定的工程設(shè)計、施工、竣工和缺陷修補(bǔ)的款額，包括以及按照合同做出的調(diào)整（如果有）。 1.1.4.2　“Cost” means all expenditure reasonably incurred (or to be incurred) by t

51、he Contractor, whether on or off the Site, including overhead and similar charges, but does not include profit. “成本（費(fèi)用）”系指承包商在現(xiàn)場內(nèi)外所發(fā)生（或?qū)l(fā)生）的所有合理開支，包括管理費(fèi)用及類似的支出，但不包括利潤。 1.1.4.3　“Final Statement” means the statement defined in Sub-Clause 14.11[Application for Final Payment]. “最終報表”系指第14.11款[最終付款的申請

52、]規(guī)定的報表。 1.1.4.4　“Foreign Currency” means a currency in which part (or all) of the Contract Price is payable, but not the Local Currency. “外幣”系指可用于支付合同價格中部分（或全部）款項(xiàng)的當(dāng)?shù)刎泿乓酝獾哪撤N貨幣。 1.1.4.5　“Local Currency” means the currency of the Country. “當(dāng)?shù)刎泿拧毕抵腹こ趟趪呢泿拧? 1.1.4.6　“Provisional Sum” means a sum (if

53、 any) which is specified in the Contract as a provisional sum, for the execution of any part of the Works or for the supply of Plant, Material or services under Sub-Clause 13.5 [Provisional Sums]. “暫列金額”系指合同中規(guī)定作為暫列金額的一筆款額（如果有），根據(jù)第13.5款[暫列金額]的規(guī)定，用于工程某一部分的實(shí)施，或用于提供生產(chǎn)設(shè)備、材料或服務(wù)。 1.1.4.7　“Retention Money

54、” means the accumulated retention moneys which the Employer retains under Sub-Clause 14.3 [Application for Interim Payments] and pays under Sub-Clause 14.9 [Payment of Retention Money]. “保留金”系指雇主根據(jù)第14.3款[期中付款的申請]的規(guī)定扣留的保留金累計金額，根據(jù)第14.9款[保留金的支付]的規(guī)定進(jìn)行支付。 1.1.4.8　“Statement” means a statement submitted

55、 by the Contractor as part of an application for payment under Clause 14 [Contract Price and Payment]. “報表”系指承包商根據(jù)第14條[合同價格和付款]的規(guī)定提交的作為付款申請的組成部分的報表。 1.1.5　Works and Goods 工程和貨物 1.1.5.1　“Contractor’s Equipment” means all apparatus, machinery, vehicles and other things required for the execution a

56、nd completion of the Works and remedying of any defects. However, Contractor’s Equipment excludes Temporary Works, Employer’s Equipment (if any), Plant, Materials and any other things intended to form or forming part of the Permanent Works. “承包商設(shè)備”系指為實(shí)施和完成工程、以及修補(bǔ)任何缺陷需要的所有儀器、機(jī)械、車輛和其他物品。但承包商設(shè)備不包括臨時工程

57、、雇主設(shè)備（如果有）、以及擬構(gòu)成或正構(gòu)成永久工程一部分的生產(chǎn)設(shè)備、材料和其他任何物品。 1.1.5.2　“Goods” means Contractor’s Equipment, Materials, Plant and Temporary Works, or any of them as appropriate. “貨物”系指承包商設(shè)備、材料、生產(chǎn)設(shè)備和臨時工程，或視情況其中任何一種。 1.1.5.3　“Materials” means things of all kinds (other than Plant) intended to form or forming part of

58、the Permanent Works, including the supply-only materials (if any) to be supplied by the Contractor under the Contract. “材料”系指擬構(gòu)成或正構(gòu)成永久工程一部分的各類物品（生產(chǎn)設(shè)備除外），包括根據(jù)合同要由承包商供應(yīng)的只供材料（如果有）。 1.1.5.4　“Permanent Works” means the permanent works to be designed and executed by the Contractor under the Contract. “

59、永久工程”系指根據(jù)合同承包商要進(jìn)行設(shè)計和施工的永久性工程。 1.1.5.5　“Plant “means the apparatus, machinery and vehicles intended to form or forming part of the Permanent Works. “生產(chǎn)設(shè)備”系指擬構(gòu)成或正構(gòu)成永久工程一部分的儀器、機(jī)械和車輛。 1.1.5.6　“Section” means a part of the Works specified in the Particular Conditions as a Section (if any). “分項(xiàng)工程”系指在專

60、用條件中確定為分項(xiàng)工程（如果有）的工程組成部分。 1.1.5.7　“Temporary Works” means all temporary works of every kind (other than Contractor’s Equipment) required on Site for the execution and completion of the Permanent Works and the remedying of any defects. “臨時工程”系指為實(shí)施和完成永久工程及修補(bǔ)任何缺陷，在現(xiàn)場所需的所有各類臨時性工程（承包商設(shè)備除外）。 1.1.5.8　“Wo

61、rks” means the Permanent Works and the Temporary Works, or either of them as appropriate. “工程”系指永久工程和臨時工程，或視情況指二者之一。 1.1.6　Other Definitions 其他定義 1.1.6.1　“Contractor’s Documents” means the calculations, computer programs and other software, drawings, manuals, models and other documents of a tech

62、nical nature supplied by the Contractor under the Contract; as described in Sub-Clause 5.2 [Contractor’s Documents]. “承包商文件”系指第5.2條款[承包商文件]中所述的，承包商根據(jù)合同應(yīng)提交的所有計算書、 計算機(jī)程序和其他軟件、圖紙、手冊、模型、以及其他技術(shù)性文件。 1.1.6.2　“Country” means the country in which the Site (or most of it) is located, where the Permanent Wor

63、ks are to be executed. “工程所在國”系指實(shí)施永久工程的現(xiàn)場（或其大部分）所在的國家。 1.1.6.3　“Employer’s Equipment” means the apparatus, machinery and vehicles (if any) made available by the Employer for the use of the Contractor in the execution of the Works, as stated in the Employer’s Requirements; but does not include Plan

64、t which has not been taken over by the Employer. “雇主設(shè)備”系指雇主要求中所述的，由雇主提供的供承包商在實(shí)施工程中使用的儀器、機(jī)械和車輛（如果有），但不包括尚未經(jīng)雇主接收的生產(chǎn)設(shè)備。 1.1.6.4　“Fore Majeure” is defined in Clause 19 [Fore Majeure]. “不可抗力”見第19條[不可抗力]的定義。 1.1.6.5　“Laws” means all national (or state) legislation, statutes, ordinances and other laws,

65、 and regulations and by-laws of any legally constituted public authority. “法律”系指所有全國性（或洲的）法律、條例、法令和其他法律，以及任何合法建立的公共當(dāng)局制定的規(guī)則和細(xì)則等。 1.1.1.6　“Performance Security” means the security (or securities, if any) under Sub-Clause 4.2 [Performance Security]. “履約擔(dān)?！毕抵父鶕?jù)第4.2款[履約擔(dān)保]規(guī)定的擔(dān)保（或各項(xiàng)擔(dān)保，如果有）。 1.1.6.7　“S

66、ite” means the places where the Permanent Works are to be executed and to which Plant and Materials are to be delivered, and any other places as may be specified in the Contract as forming part of the Site. “現(xiàn)場“系指將實(shí)施永久工程和運(yùn)送生產(chǎn)設(shè)備與材料到達(dá)的地點(diǎn)，以及合同中可能指定為現(xiàn)場組成部分的任何其他場所。 1.1.6.8　“Variation” means any change to the Employer’s Requirements or the Works, which is instructed or approved as a variation under Clause 13 [Variation and Adjustment]. “變更”系指按照第13條[變更和調(diào)整]的規(guī)定，經(jīng)指示或批準(zhǔn)作為變更的，對雇主要求或工程所做的任何更改。 1.2　Interp